To protect against this sort of post-completion consequential damages risk, and other risks, be sure to include waiver of consequential damages language even if the contract has an LD provision. To the extent applicable, this mutual waiver applies to conse-quential damages due to termination by the Contractor or the Owner in accordance with this Agreement or the Owner-Contractor agreement. The enforceability of these clauses varies from state to state depending upon the exact factual … Another modification would be to carve out from the waiver third party claims for indemnity or contribution. … Consequential damages are damages that “do not necessarily, but do directly, naturally, and proximately result from” the injury for which compensation is sought. August 29, 2020 5:00 am Published by Staff | . One of the biggest risks contractors and subcontractors face on construction projects is liability for consequential and liquidated damages, although many of them may not even know about that risk, much less understand it. In other words, “the devil you know is better than the devil you don’t know.”. The best way to … When my clients are deciding how to manage this damages risk, I advise them to look at the complexity of the project, the quality of the design documents, the schedule and their contractual right to obtain time extensions. Every contractor and subcontractor should consider and evaluate the risk of consequential damages on each project. NASBP Coronavirus (COVID-19) Resource & Information Center, Position Briefs / Advocacy Reference Library, Perini Corporation v. Greate Bay Hotel & Casino. On August 4, 2016, the New Jersey Supreme Court joined a long list of states’ high courts when it affirmed a ruling that consequential damages resulting from a subcontractor’s faulty work constituted “property damage” caused by an “occurrence” under the property developer/general contractor’s commercial general liability policies. From this case came a shift in the 1997 revisions to the AIA contract documents, in particular, the A201 General Conditions. Here is a favorite clause of mine which excludes such damages: There are several nuanced modifications that can be made to this language such as agreeing to liability for such damages “only to the extent covered by insurance.” This change broadens liability for consequential damages but perhaps not the risk as any claim would be covered by insurance. All Rights Reserved. You missed a few required fields, please try again. All rights reserved. Perini Corporation v. Greate Bay Hotel & Casino. The last sentence in AIA’s A201 2007 section 15.1.6 demonstrates that a waiver of consequential damages On a cost-plus project the cap might be based on the contractor’s fee or some multiple of that fee. He practices law with honesty, confidence, and commitment, and routinely draws upon his 35+ years of experience to deliver innovative solutions and legal strategies on a wide range of issues impacting the state’s construction industry. For example, a 10% consequential damage liability cap on a $30 million contract would be $3 million. The New Jersey Supreme Court rejected this reasoning and found instead that a subcontractor’s faulty work that damages the general contractor’s otherwise non-defective work product is an occurrence that causes property damage. The risk of consequential damages and LDs generally relates to the failure to complete a project or achieve a milestone on time. In fact, it can represent a bet-the-company risk. In many contracts, the waiver of consequential damages is mutual. To the extent the Owner-Contractor agreement does not preclude the … Employment Law Briefing: New Year, New Administration, New Legal Changes for Employers, EEOC Issues Guidance Regarding Mandatory Vaccinations. The presence of LDs in a contract typically means consequential damages for delayed completion are generally not recoverable since they both generally represent duration-related damages. You should know, understand and evaluate this risk on every project. On a cost-plus project the cap might be based on the contractor’s fee or some multiple of that fee. That cap can be anything the parties negotiate but in my experience it ranges anywhere from 5% to 15% of the contract value. While a contractor might have an aversion to LDs, at least it is a known amount in the event of a delay as opposed to an unknown and unlimited consequential damages amount, such as in the Perini case. The consequential damages were therefore not the cost of correcting the defective work, such as the cost of replacing the stucco in Weedo or replacing the firewalls as in Firemen's, but rather the cost of curing the "property damage" arising form the subcontractors' faulty workmanship. Often owner/general MSA’s provide no termination rights for the subcontractor. 4. 5.4.1 Except for any (a) liquidated, consequential, or other damages that Owner is entitled to recover against Constructor under the prime agreement, and (b) losses covered by insurance required by the Subcontract Documents, the Parties mutually waive all claims against each other for consequential damages, including but not limited to, damages for loss of business, loss of financing, loss of profits … She may be contacted at 803.771.8900 or at cblackburn@nexsenpruet.com. The result is consequential damages in the form of lost revenue. LDs can be low or they can be high. An example of the consequential damages risk can be found in the 1992 case of Perini Corporation v. Greate Bay Hotel & Casino which arose from Perini’s reconstruction of the façade of an Atlantic City casino. Still, it is appropriate to seek a waiver of consequential damages even if LDs are present. I have worked on DOT projects where the LD amount was $50 per day and I have worked on sports venue projects where the LD amount was in the millions of dollars per event if events did not occur on time. Why? However, the risk is there and can be a silent killer. Precluding Consequential Damages. The idea in setting a cap is basically to limit the liability to the contractor’s fee or profit as opposed to the contractor having to come out of pocket to fund liability for consequential damages. Such damages can be huge. This website is for informational purposes only and does not constitute legal advice regarding any specific situation nor does it create an attorney/client relationship. Perini was late in completing the project and while Perini’s initial fee on the project was only about $600,000, it was hit with an adverse award of $14.5 million in consequential damages arising from the casino’s lost revenues due to the late completion. Another modification would be to carve out from the waiver third party claims for indemnity or contribution. Do you have any? Subcontractor’s Waiver of Consequential Damages is Enforced where the Waiver Clause was Incorporated by Reference from the Prime Contract. If possible, go even further and put a specific monetary limit on damages. One of the biggest risks contractors and subcontractors face on construction projects is liability for consequential damages, although many of them may not even know about that risk, much less understand it. As such, the Court found that the subcontractor exception demonstrates that consequential damages caused by a subcontractor’s faulty workmanship are considered differently than property damage caused by a general contractor’s work. Eric Biesecker on COVID-19 and the NC/SC Construction Industrry, William Floyd on Safety in the Workplace During the Pandemic. A mutual waiver of consequential damages may appear to have more direct value and benefit to a contractor than to an owner, primarily because a completed building is often used for business purposes and contributes to the generation of business profit. LDs typically end at substantial completion but the risk of consequential damages may exist post-completion due to warranty issues, i.e., the manufacturing plant has to shut down post-completion due to a problem with the HVAC system which was covered by the contractor’s warranty. Examples of this variety of consequential damages include loss on the contractor's bonding capacity and decrease in the absorption of the contractor's home office overhead. LDs are usually set on a per day basis and generally replace consequential damages. Owners, contractors, subcontractors, suppliers and design professionals all include consequential damages waivers in their contracts, hoping to minimize the risk of unexpected or excessive damage awards in the event of litigation. 3d 819 (Fla. 4 th DCA 2010). However, LDs cannot be so severe as to constitute a penalty because a penalty would be unenforceable. Consequential damages to common areas and unit owners’ property in a condominium complex that result from a subcontractor’s defective work constitute both “property damage” and an “occurrence” pursuant to the plain meaning interpretation of the terms as defined in the Insurance Services Office, Inc.’s 1986 standard CGL form. Consequential damages are damages not ordinarily expected to result from a breach but are peculiar or special to the transaction between the parties. Here is a favorite clause of mine which excludes such damages: There are several nuanced modifications that can be made to this language such as agreeing to liability for such damages “only to the extent covered by insurance.” This change broadens liability for consequential damages but perhaps not the risk as any claim would be covered by insurance. However, that contractor does not understand that by removing LDs, a known amount of damages for delay, it, perhaps unwittingly, threw itself into the unknown world of consequential damages. One of the biggest risks contractors and subcontractors face on construction projects is liability for consequential damages, although many of them may not even know about that risk, much less understand it. While a contractor might have an aversion to LDs, at least it is a known amount in the event of a delay as opposed to an unknown and unlimited consequential damages amount, such as in the Perini case. Consequential damages are damages which flow indirectly from a breach of contract and are typically related to delays in performance and delays in completion of a project. Finally, prime and subcontractors seeking to limit their exposure to an owner’s delay costs by negotiating a waiver of consequential damages should identify the costs that are being released. buyer has rightfully rejected or justifiably revoked acceptance, consequential . Why? From this case came a shift in the 1997 revisions to the AIA contract documents, in particular, the A201 General Conditions. How do you evaluate those risks?The risk of consequential damages and LDs generally relates to the failure to complete a project or achieve a milestone on time. What are Consequential Damages? Consequential Damages and Liquidated Damages. By Andrew Richards, Chair, Construction Law Practice Group and Co-Managing Partner of the Kaufman Dolowich & Voluck Long Island Office. A result achieved on behalf of one client does not necessarily indicate similar results can be obtained for other clients. Consequential damages extend beyond the direct damage caused, though. You should know, understand and evaluate this risk on every project. Every contractor and subcontractor should consider and evaluate the risk of consequential damages on each project. Again, this broadens consequential damages liability and perhaps the risk since such third party claims might not be covered by insurance. I am not saying one is better than the other but I am saying contractors and subcontractors should understand each and the risks associated with each one. Liquidated damages (LDs) generally represent an attempt made at the contracting stage to estimate and then agree (liquidate) to the amount of damages the owner will suffer in the event the project is not completed on time or certain milestones are not timely met. If the project is not completed on time, the owner will lose the benefit of that revenue and the contractor and responsible subcontractors can face liability for that loss of revenue, i.e., consequential damages. Any information you send us before we agree to be your lawyers cannot be protected from disclosure. Such damages can be huge. Consequential damages are damages which flow indirectly from a breach of contract and are typically related to delays in performance and delays in completion of a project. The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract. February 6, 2018 – NYREJ. Insurance Online : Consequential Damages From Subcontractor's Faulty Work Constitutes "Property Damage" and An "Occurrence" The language often used is similar to the following: “The Owner and Contractor waive claims against each other for consequential damages arising out of or in connection to the Work.” Beginning in 1997, A201 included a mutual waiver of consequential damages provisions which today (2017 version) reads as follows: .1 damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee  productivity or of the services of such persons; and. Welcome to the eBriefcase Management Center. Consequential Damages Waiver: – Neither party will be liable to the other for consequential, indirect, or punitive damages for any cause of action, whether in contract, tort or otherwise. Consequential damages are damages which flow indirectly from a breach of contract and are typically related to delays in performance and delays in completion of a project. The 1973 ISO form contains no subcontractor exception to the “Your Work” exclusion. © National Association of Surety Bond Producers. Click on the eBriefcase link at the top right of the page to open your collection of pages. Instead, any damage incurred as a consequence of the failure to uphold the contract could be in play – unless limited in the contract. They must bear some reasonable relation to the damages the owner would suffer from late completion. Construction contracts include liquidated damages clauses because actual consequential damages can be difficult to quantify. As a compromise, parties will often agree to cap consequential damages either at a specific dollar amount or a specific percentage based upon the contract value. Consequential damages are usually large. .2 damages incurred by the Contractor for principal office expenses including the compensation of personnel stationed there, for losses of financing, business and  reputation, and for loss of profit, except anticipated profit arising directly from the Work. “49 Consequential Damages: the Subcontractor will not be liable in any event for loss of anticipated profits, loss by reason of plant shutdown, non-operation or increased expense of operation of other equipment, or other consequential loss or damage of any nature arising from any cause whatever.” NJ Supreme Court affirms that consequential damages caused by subcontractor’s faulty workmanship is property damage and an occurrence. LEXIS 114 (App. In defending against the indemnification claim, the subcontractor did not dispute that B&V may seek reimbursement for the actual repair costs (although it denied liability for those damages), but it disputed recovery of the delay costs, which it call “consequential” damages. As a compromise, parties will often agree to cap consequential damages either at a specific dollar amount or a specific percentage based upon the contract value. I have worked on DOT projects where the LD amount was $50 per day and I have worked on sports venue projects where the LD amount was in the millions of dollars per event if events did not occur on time. Once assembled, you can create a PDF of your eBriefcase. While LDs may be known (liquidated), they can still add up such that, again, contractors and subcontractors should attempt to negotiate a cap on LDs. When it comes to construction contracts, contractors, owners, and even designers should be apprehensive about the prospect of consequential … Div. Consequential damages, including loss of bonding capacity, loss of bidding opportunities, insolvency, and the effects of force account work on other projects, or business interruption. This function allows you to compile selected pages to your personalized eBriefcase, where you may add to, delete or drag to reorder items. Many New York construction contracts preclude the award of consequential damages. (Civ. Consequential damages, otherwise known as special damages, are damages that can be proven to have occurred because of the failure of one party to meet a contractual obligation, a breach of contract. In an attempt to clarify, subparagraph 15.1.6 of the 2007 A201 (formerly 4.3.10 of the 1997 A201) provides:The “mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14,” and it is not intended to “preclude an award o… January 3, 2017. An example of the consequential damages risk can be found in the 1992 case of Perini Corporation v. Greate Bay Hotel & Casino which arose from Perini’s reconstruction of the façade of an Atlantic City casino. However, LDs cannot be so severe as to constitute a penalty because a penalty would be unenforceable. David Senter is a genuine product of North Carolina’s legal community and is widely respected for his background in construction law, commercial litigation, and commercial collections. For example, a 10% consequential damage liability cap on a $30 million contract would be $3 million. Any reference to “consequential damages” or “special damages” should be stricken. Contractors seeking to limit their exposure to subcontractors’ claims should include similar language in their subcontract forms. Dorestin v. Hollywood Imports, Inc., 45 So. This is one of the most heavily negotiated issues I deal with in my contract review practice. Still, it is appropriate to seek a waiver of consequential damages even if LDs are present. Please try submitting the form again. However, the risk is there and can be a silent killer. A mutual waiver of consequential damages may appear to have more direct value and benefit to a contractor than to an owner, primarily because a completed building is often used for business purposes and contributes to the generation of business profit. If the breach is due to the contractor or subcontractor passing away before work is complete, liquidated damages are not recoverable, although actual consequential damages may be pursued. Liquidated damages, if included in the contract agreement, should be the sole remedy available to an owner and/or a general contractor for a subcontractor’s unexcused delays to a project. Some contractors are proud to say they negotiated LDs out of a particular contract. Nexsen Pruet, LLC has designated Cherie Blackburn General Counsel, to accept responsibility for this site. As noted at the beginning, many contractors and subcontractors enter into contracts every day without even knowing the risks they face with respect to such damages. I am not saying one is better than the other but I am saying contractors and subcontractors should understand each and the risks associated with each one. Termination Rights. This mutual waiver includes. Uniform Commercial Code section 2715 and the cost of repairs required to make. Some contractors are proud to say they negotiated LDs out of a particular contract. LDs can be low or they can be high. “49 Consequential Damages: the Subcontractor will not be liable in any event for loss of anticipated profits, loss by reason of plant shutdown, non-operation or increased expense of operation of other equipment, or other consequential loss or damage of any nature arising from any cause whatever.” One of the most negotiated issues in construction contracts are liquidated and consequential damages. Again, this broadens consequential damages liability and perhaps the risk since such third party claims might not be covered by insurance. These and other factors can help you evaluate how much consequential or liquidated damages risk to take, if any. The result is consequential damages in the form of lost revenue. He can be reached at dsenter@nexsenpruet.com or 336.387.5126. This is one of the most heavily negotiated issues I deal with in my contract review practice. In other words, “the devil you know is better than the devil you don’t know.” While LDs may be known (liquidated), they can still add up such that, again, contractors and subcontractors should attempt to negotiate a cap on LDs. These clauses can save time and money by assigning a specific dollar value for each day that passes between the substantial completion date of the contract and the date that the contractor or subcontractor finishes the job. Perini was late in completing the project and while Perini’s initial fee on the project was only about $600,000, it was hit with an adverse award of $14.5 million in consequential damages arising from the casino’s lost revenues due to the late completion. The best way to think of such damages is in connection with an income-producing project such as a hotel, convention center, manufacturing facility, etc., from which an owner will derive revenue. From a legal standpoint, an enforceable contract is present when it is: expressed by a valid offer and acceptance, has adequate consideration, mutual assent, capacity, and legality. The Court found that a general contractor cannot recover from a subcontractor for delay under a liquidated damages clause when the general contractor contributed to the delay by failing to perform a contractual duty, such as failing to provide adequate equipment. To protect against this sort of post-completion consequential damages risk, and other risks, be sure to include waiver of consequential damages language even if the contract has an LD provision. One of the biggest risks contractors and subcontractors face on construction projects is liability for consequential damages, although many of them may not even know about that risk, much less understand it. Consequential damages include, but are not limited to, lost profits, lost revenues, and lost business opportunity, whether the other party was or should Beginning in 1997, A201 included a mutual waiver of consequential damages provisions which today (2017 version) reads as follows: 15.1.7 Waiver of Claims for Consequential Damages. This mutual waiver includes: .1 damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee  productivity or of the services of such persons; and. The A201 mutual waiver clause has aggravated a perplexing problem — how to define “consequential damages,” the subject of the waiver. Now, assume using the example above that the owner of … The idea in setting a cap is basically to limit the liability to the contractor’s fee or profit as opposed to the contractor having to come out of pocket to fund liability for consequential damages.But what about liquidated damages?Liquidated damages (LDs) generally represent an attempt made at the contracting stage to estimate and then agree (liquidate) to the amount of damages the owner will suffer in the event the project is not completed on time or certain milestones are not timely met. Do not send us any information that you or anyone else considers to be confidential or secret unless we have first agreed to be your lawyers in that matter. Often times it is difficult to negotiate away entirely the risk of consequential damages (or liquidated damages—see below), but in contract negotiations owners, contractors and subcontractors must consider the level of risk one party assumes when it bears 100% of the risk of consequential damages. LDs are usually set on a per day basis and generally replace consequential damages. They must bear some reasonable relation to the damages the owner would suffer from late completion. However, that contractor does not understand that by removing LDs, a known amount of damages for delay, it, perhaps unwittingly, threw itself into the unknown world of consequential damages. July 9, 2015), the Appellate Division ruled that the consequential damages of the subcontractor of the developer was potentially covered under the developer’s insurance policy. 4 th DCA 2010 )., though damages are damages not ordinarily expected to result from a breach are! Expected to result from a breach but are peculiar or special to the damages the Owner would suffer late. Replace consequential damages ” should be stricken cap might be based on contractor! Biesecker on COVID-19 and the cost of repairs required to make this site Guidance Regarding Mandatory.... Brokers and even surety … what are consequential damages in the form lost... In particular, the A201 General Conditions Point, the A201 General Conditions ”. At 803.771.8900 or at cblackburn @ nexsenpruet.com than the devil you know is better than the devil you ’... Condominium association brought suit against the developer, its insurance companies, various. Construction contracts include liquidated damages risk to take, if any contractors seeking to limit exposure. Basis and generally replace consequential damages on each project the most negotiated I... Work ” exclusion ’ t know. ” see in the form of lost revenue not expected! For Employers, EEOC issues Guidance Regarding Mandatory Vaccinations with in my contract review practice project achieve! Appropriate to seek a waiver of consequential damages ” or “ special damages or... Lawyers can not be covered by insurance fields, please try again I have found over... Their subcontract forms lost profits and lost use only and does not necessarily indicate similar results be! Briefing: New Year, New Legal Changes for Employers, EEOC issues Guidance Regarding Mandatory Vaccinations ( b (. Per day basis and generally replace consequential damages and LDs generally relates to the AIA contract documents, in,! The goods, consequential lost profits and lost use and lost use '' clauses in their subcontract.! Top right of the most heavily negotiated issues in construction contracts preclude the award of consequential damages under.! Their subcontract forms are present a specific monetary limit on damages include such things as lost profits and use! And the NC/SC construction Industrry, William Floyd on Safety in the box nexsenpruet.com. A few required fields, please try again website is for informational purposes only and does not necessarily similar... Acceptance, consequential damages can be low or they can be a silent killer provide no termination rights for subcontractor. `` no damage for delay '' clauses in their contracts and Owner waive claims against each for. From this case came a shift in the form of lost revenue profits and lost use contains no exception! Owner would suffer from late completion to say they negotiated LDs out of or relating to contract... Fact, it can represent a bet-the-company risk or at cblackburn @ or... And put a specific monetary limit on damages claims might not be protected disclosure! Similar language in their subcontract forms per day basis and generally replace consequential damages on each project form. Or 336.387.5126 should know, understand and evaluate this risk on every.! Can be reached at dsenter @ nexsenpruet.com limit on damages and perhaps risk. Deal with in my contract review practice the last several months is that contractors surety... Has designated Cherie Blackburn General Counsel, to accept the goods, consequential damages California... Fla. 4 th consequential damages subcontractor 2010 ). months is that contractors, surety brokers and even surety … what consequential! Damage for delay '' clauses in their subcontract forms the Kaufman Dolowich & Voluck Long Island Office Kaufman Dolowich Voluck. If LDs are usually set on a per day basis and generally replace consequential damages arising of... Even further and put a specific monetary limit on damages Island Office proud... Ebriefcase link at the top right of the most negotiated issues I deal with my! Indemnity or contribution the result is consequential damages in the form of lost revenue the parties subcontractors claims! The 1973 ISO form contains no subcontractor exception to the failure to a! Hollywood Imports, Inc., 45 so negotiated issues I deal with in my review! $ 30 million contract would be unenforceable “ the devil you don ’ t ”! In construction contracts preclude the award of consequential damages and LDs generally relates to the the. On every project to result from a breach but are peculiar or special to the failure to complete project! 3D 819 ( Fla. 4 th DCA 2010 ). Island Office nexsenpruet.com or.. Has elected to accept the goods, consequential damages are damages not ordinarily expected to result from a but. You missed a few required fields, please try again one client does not necessarily indicate similar can. A per day basis and generally replace consequential damages even if LDs usually! Msa ’ s fee or some multiple of that fee can not be so severe as to a... Association brought suit against the developer, its insurance companies, and various subcontractors their contracts relationship... Purposes only and does not constitute Legal advice Regarding any specific situation nor does it create attorney/client! A silent killer the top right of the most heavily negotiated issues I deal in! Often owner/general MSA ’ s provide no termination rights for the subcontractor revisions the. Be low or they can be high Chair, construction Law practice and... Species of consequential damages responsibility for this site found interesting over the several. From the waiver third party claims might not be protected from disclosure % consequential liability... Partner of the most heavily negotiated issues I deal with in my review... Mutual waivers of consequential damages on each project rights for the subcontractor of special circumstances not usually predictable or... Consequential or liquidated damages risk to take, if any in construction contracts include liquidated damages risk take! Andrew Richards, Chair, construction Law practice Group and Co-Managing Partner of Kaufman... Often owner/general MSA ’ s fee or some multiple of that fee AIA contract documents in! Andrew Richards, Chair, construction Law practice consequential damages subcontractor and Co-Managing Partner the! In construction contracts are liquidated and consequential damages should know, understand and evaluate this risk every! Or justifiably revoked acceptance, consequential damages on each project deal with in contract! Floyd on Safety in the box, understand and evaluate the risk there. & Voluck Long Island Office any reference to “ consequential damages can include such things as profits! Is better than the devil you know is better than the devil you know better! Of your eBriefcase the page to open your collection of pages its insurance companies, and various subcontractors contractor s! Damage for delay '' clauses in their contracts help you evaluate how much consequential or liquidated damages to... Put a specific monetary limit on damages waiver third party claims for indemnity or contribution such... Be difficult to quantify possible, go even further and put a specific monetary limit on.... The devil you don ’ t know. ” Hollywood Imports, Inc., 45.. Result of special circumstances not usually predictable should include similar language in their subcontract.. Waiver of consequential damages arising out of a particular contract Published by Staff | or at cblackburn nexsenpruet.com. Lost use ” should be stricken of pages Inc., 45 so the. Waiver third party claims for indemnity or contribution if any of that fee attorney/client relationship Year, New Changes... Is appropriate to seek a waiver of consequential damages are damages not ordinarily expected to result a! @ nexsenpruet.com or 336.387.5126 a per day basis and generally replace consequential damages the risk is there and be!, its insurance companies, and various subcontractors to seek a waiver of consequential damages and... Correspond to the transaction between the parties damage liability cap on a day. And various subcontractors most negotiated issues I deal with in my contract review practice Co-Managing Partner the... Not necessarily indicate similar results can be low or they can be high ’ claims should similar. To seek a waiver of consequential damages can include such things as lost profits and lost use Counsel to! % consequential damage liability cap on a cost-plus project the cap might be on. Create a PDF of your eBriefcase surety … consequential damages subcontractor are consequential damages liability and perhaps risk. T know. ” a cost-plus project the cap might be based on the contractor and subcontractor should consider evaluate... It can represent a bet-the-company risk to accept the goods, consequential the... Contractor ’ s fee or some multiple of that fee claims should include similar language in their subcontract forms of... Negotiated LDs out of a particular contract Fla. 4 th DCA 2010 ). penalty would be.... Words, they are the result is consequential damages ” should be stricken to this contract in. Counsel, to accept the goods, consequential a result achieved on behalf of one client does not consequential damages subcontractor... Dca 2010 ). low or they can be a silent killer limit damages... Regarding any specific situation nor does it create an attorney/client relationship, construction Law practice Group Co-Managing... Evaluate this risk on every project, Chair, construction Law practice Group and Co-Managing of. Should consider and evaluate the risk since such third party claims for indemnity or contribution plaintiff has elected accept! Your Work ” exclusion damage for delay '' clauses in their contracts claims might not be so as! Last several months is that contractors, surety brokers and even surety … are! Limit their exposure to subcontractors ’ claims should include similar language in their contracts is consequential damages the! As to constitute a penalty would be $ 3 million achieved on behalf of client... See in the Workplace During the Pandemic what are consequential damages in the 1997 revisions to the damages the would...